BUILDERS REGISTRATION AND HOME OWNERS S. 34;Board" means the Builders Registration Board of Queensland constituted under this Act;. a) which is registered as such with the Local Authority of the Area in which it is situated; or. b) which is used or intended is to be used for the purpose of accommodation by three or more occupiers other than the owner of the building, members of his family or any employee of his; 34; "General Fund" means the Builders Registration Board General Fund established and maintained by the Council under this Act;.
Subject to this Act, the board's functions are-. a) to issue and cancel certificates of registration as registered builders;. The chairman of the board of directors is appointed by the governor of the central bank in accordance with section 10, subsection 2, said notification.
0 he becomes bankrupt or benefits from the laws relating to bankruptcy;. g) is dismissed from office by the Governor in Council. If a casual vacancy occurs in the office, a member of the Board during his currency.
19 REGISTRATION OF BUILDERS AND S. OF HOUSE OWNERS. 1) The Chairman of the Board shall preside at every meeting of the Board in which he is present. No act or procedure of the Board shall be repealed merely because there has been a vacancy.
Persons who may be registered as registered house builders
30 REGISTRATION OF HOUSE BUILDERS AND OWNERS. or property of or under the control of the Board which is or appears to have been stolen or willfully destroyed or damaged;. 3 1 ~ REGISTRATION OF HOUSE BUILDERS AND OWNERS. 6) With and from the commencement of the Builders Registration and Homeowners Protection Amendment Act 1982, the Board shall not make or cause to be made an entry in the register purporting to show that a firm or partnership is registered. builder.
Persons who may be registered as registered general builders
34 BUILDING REGISTRATION AND HOMEOWNERS S. b) be supported by such evidence, including evidence of financial resources, as the board requires;. The Board may subject any registration as a registered developer to such other conditions and restrictions as it deems appropriate.
24 s.35 BUILDERS REGISTRATION AND HOME OWNERS. b) has failed to comply with a condition or restriction to which his registration is subject. or that a condition or restriction is no longer necessary, the Council may by its order-.
3 6 ~ REGISTRATION OF HOUSE BUILDERS AND OWNERS. b) the construction of the building undertaken by the body corporate is managed and supervised at all times by an individual acting in the capacity and competent to assume and assume the authorities, duties and responsibilities of a nominee; and. c) a notice referred to in section 3 6 ~ (4) is given, in the prescribed form, to the Board as soon as possible. A body corporate may appoint more than one fit and proper individual to be its nominees in accordance with the provisions of this subsection. This section applies without prejudice to any liability imposed under this Act on a body corporate which has carried out or caused to be carried out construction works to which an appointment as a nominee of the body corporate relates.
Roll of registered builders. (1) In the month of January in each year the Board shall furnish to the Minister a roll of registered builders
A registered builder may request in writing that his name be removed from the Register and the a Council may, if it thinks fit, decide that the name of that registered builder be so removed. Service of a notice referred to in this subsection may be proved by the oath of the person who made the service or by affidavit. a) in the case of an order made under clause (c), the registration of the registered builder against whom it is made is subject to the conditions and restrictions ordered until the order is revoked or modified as prescribed;. 32 s.46 BUILDERS REGISTRATION AND HOME OWNERS. c) in the case of an order made under clause (e), the registered builder shall cease to be registered in terms of this Act until the order is revoked as prescribed.
Surrender of certificate of registration suspended or cancelled
The appellant shall institute his appeal by submitting written notice of his grounds of appeal to the Magistrate's Court and serving a copy of that notice on the Council. 1 ) Every magistrate's court has jurisdiction to hear and decide an appeal made or returned to it. it in terms of this Act. Unless the court which is to hear and decide an appeal, with the consent of the Council and the appellant, directs an appeal, with the consent of the Council and the appellant, orders otherwise, every appeal shall be by way of retrial.
BUILDERS
- Building construction by body corporate. (1) Where building construction is undertaken by a body corporate that is registered as a
- Sign to be erected. (1) A registered builder shall cause to be affixed or erected in a conspicuous position on the site of building
- Offences by persons not registered as registered builders or concerned with building construction who are not so registered. ( 1 ) A
- Exemption of certain persons who perform building construction
- Powers of court on appeal. The court hearing an appeal under section 60 may-
- Offence to disobey order under section 59. A person who- (a) fails to comply with the order of the Board made under
If it seems to the judge in the Chamber that the construction of the building in question has started or is being carried out in violation of any of the provisions of this law, he must-. a) make a temporary order of the description requested by the applicant;. 5 2 ~ REGISTRATION OF BUILDERS AND S. HOUSE OWNERS work in connection with the construction of the building or the construction of the house to which it is connected;. 55 REGISTRATION OF BUILDERS AND S. OF HOUSE OWNERS. b) causes the completion of that house building that is directed and supervised personally by him.
TO BENEFIT HOME OWNERS
A person who (a) fails to comply with the order of the Board under (a) fails to comply with the order of the Board under. 65 BUILDING REGISTRATION AND HOMEOWNERS Residential structures valued at more than $3,000, whether under contract or otherwise, shall be notified to the Board of Directors or an agent of the Board of the construction of such residential structure. A registered housebuilder who intends to carry out housebuilding of a value exceeding $3,000, whether under contract or otherwise, must pay to the Council or an agent of the Council an insurance premium in respect of the housebuilding of or to any dwelling in an amount calculated according to the prescribed scale.
Payment of insurance premium to be noted on building approval
This notice must be in the prescribed form and must contain the prescribed information, which includes the proposed date of commencement and the proposed date of practical completion of the construction of the house. Such insurance premium shall be paid-. i) if there is a contract for the execution of this construction of the house, within 14 days after the conclusion of this contract; ii) when this construction of the house is carried out differently than in accordance with the contract, at least 14 days before the start of the construction of this house. 66 REGISTRATION OF BUILDERS AND HOUSE-OWNERS b) no amount shall be payable under this section in respect of the construction of a building.
67 REGISTRATION OF BUILDERS AND HOME OWNERS S. the rights of this party under this part in connection with the insurance of the construction of the house. 1 ) Whether or not section 64, 66 or 67 is complied with, the board of directors shall be deemed to have entered into a contract (called a contract of sale) with each purchaser and thereby assumed the insurance risk provided for in the following subsections and in the prescribed form sales contracts. 70 REGISTRATION OF CONSTRUCTION AND HOME OWNERS. 11) the administration receives a written notification of the error from the customer within three months after learning about the error;. ii) if the loss or damage is due to a defect in the residential building to which the cover applies, which is not a major defect or is a major defect of which the buyer should have known for reasonable reasons before the expiration of six months from the date of practical completion of the construction of the house or before at the end of such an extended period as the council allows in individual cases, only if-
Recovery of payments made under house-purchaser's agreement
71 REGISTRATION OF BUILDERS AND HOME OWNERS S. concerns the insurance risk assumed by the administration in accordance with the house purchase contract; and. An instrument evidencing any agreement or contract entered into by the Board under this section shall be exempt from the payment of stamp duty under the Stamp Duty Act. For the purposes of this Act, the date of conclusion of the contract referred to in provision (a) of Article 64(1) is -. a) if no such date has been fixed by the Board under section 72 (I), the date shown on the said notice.
76 REGISTRATION OF HOUSE BUILDERS AND OWNERS. the beginning of the construction of the building of the house that includes or is located in the dwelling on the plot. 77 subsection S. REGISTRATION OF BUILDERS AND HOME OWNERS, be deemed to have been given as if he were a party to the contract purporting to contain the warranty. This section shall have effect notwithstanding anything contained in the building contract or the contract for the sale of land.
Restriction on extent of insurance cover and warranty
Anyone who violates or fails to comply with a provision of this Act commits an offense against this Act. Proceedings for the recovery of fees payable under this Act shall be summary proceedings under the Judiciary Act 1886-1979 on appeal by a person generally or in a particular case authorized in writing by the Board. Any fine paid by a person on conviction for an offense against this Act shall be paid to the Board.
Disciplinary action against registered builders in addition to penalty. The fact that a registered builder has incurred a penalty on
A person who assaults, resists, obstructs a member of the Council or any other person who, in terms of this Act or a written authorization granted to him by the Chairman of the Council, performs a duty or exercises a duty or prevent. power for the purpose of this Act, or attempts to do so, commits an offense against this Act. 1. 86 BUILDERS REGISTRATION AND HOME OWNERS. 2) Where an obligation is imposed on a legal person by this Act, it is deemed that a similar obligation is thereby imposed on each director or member of the management board of the legal person:. 1) The Council may, by its written notice, order a person to deliver to him, within the time specified in the notice, the books, documents, documents and records specified in the notice or of a class specified in the notice provided and relating to a matter within the jurisdiction of the Council.
9 3 ~ BUILDING REGISTRATION AND HOMEOWNERS. Such directions shall, in accordance with their scope, have the force and effect of the Rules of the Court drawn up for the purposes of the appeal. 94 BUILDING REGISTRATION AND HOMEOWNERS. shall serve as evidence and, in the absence of evidence to the contrary, as conclusive proof of the matters contained therein. 3) (a) Monies to the benefit of the Home Builders Registration Commission7 in its General Fund at the inception of.
Existing staff to become Board employees. (1) Upon the commencement of this Act-
102 BYGGERTEDNING OG HUSMEJERS S. its term as a house buyer's agreement, which is deemed to have been entered into by the board under this Act. Upon the entry into force of this Act-. a) any right or entitlement that the Builders Registration Board or the House Builders Board has, is thereby divested from this board and is a right or entitlement for the board. Given under the common seal of The Builders' Registration Board of Queensland in the presence of.
INDEX
BUILDERS' REGISTRATION AND HOME-OWNERS' PROTECTION ACT 1979-1987
Building work that is defective or unsatisfactory - meaning of the term according to section The capacity of the board and members to exercise multiple jurisdictions. Guarantee and indemnity letter Deputy chairman of the board of directors-. meaning of term D~sclpllnar); action-. against registered builder in addition to penalty D~dissolution of boards. General builder- meaning of term General building~ng construction- .. meaning of term General Fund- . meaning of the term governor in council~l-. approval of, I F undcrwr~t~ng contract* . may appoint pcrton- to be deputy member to fill casual vacancy.
